测绘协议书怎么写呢？不知道的小伙伴来看看小编今天的分享吧!
测绘协议书书写格式：
1、测绘项目基本情况；
2、测绘主要内容；
3、执行技术标准；
4、完成时限；
5、测绘项目费用；
6、甲乙双方的义务；
7、违约责任；
8、签署人及证明人的的基本信息，包括姓名、身份证号码、住址、联系电话等等。
这是测绘协议书范本的模板，希望对您有帮助。您也可以点击这里直接下载文档
测绘协议书范本
委托方（甲方）：
承揽方（乙方）：
根据《民法典》《中华人民共和国测绘法》及其他相关法律法规的规定，经甲、乙方协商一致，签订本合同。
一、测绘范围及内容（包括测绘项目和工作量等）
1、测区地点：
2、测绘面积：
二、执行技术标准
三、测绘工程费用的计算与结算（包括测绘工程费用结算的依据）
执行国策财字[XXXX]XX号文件收费标准。测绘工程完成后，以实际测量面积为准，计算并一次性结清测绘工程费用。
3、测绘工程费用详见《测绘项目费用结算表》。
四、甲方的义务
1、保证乙方的测绘队伍顺利进入现场工作，提供测量必要的条件。
2、向乙方提供有关资料及技术要求。严格履行本合同甲方的其他义务。
五、乙方的义务
1、收到甲方的有关资料和技术要求后，组织测绘队伍进场作业。应按合同工期完成测绘项目工程。严格履行本合同乙方的其他义务。
六、甲方违约责任
1、如因甲方不履行合同导致一切后果，由甲方自行承担。甲方应按合同约定期限支付测绘工程款，如延期应按延误天数
2、和当时银行贷款利率计算，并向乙方支付测绘工程款10%的违约金。
七、乙方违约责任
1、乙方提供的测绘成果质量不合格，乙方应无偿给予不测或采取补救措施，达到质量要求为准。
2、乙方未按期完成测绘工作，应按超出一天扣乙方1%工程款计算。
八、附则
1、本合同由双方代表签字，加盖双方公章或合同专用章后即生效。全部测绘成果交接完毕和测绘工程款结算完成后，本合同终止。
2、本合同一式两份，甲、乙方各执一份，两份合同具有同等法律效力。
甲方：
甲方代表人或委托人（签章）：
乙方：
乙方代表人或委托人（签章）：
年月日
请注意：因为转码原因，部分文档内容可能会丢失几个字而使得文档有瑕疵，请务必从头到尾看一遍确认没有问题后再使用，本内容来源：www.51dongshi.com，20余万各类合同下载，同时还提供各类公司常用表格、文档如：入职表格、财务统计表等。
下载文档2000版测绘合同（中英文对照）
2000版测绘合同
SURVEYING AND MAPPING CONTRACT
学术交流请私信或评论留言
目录 TABLE OF CONTENTS
第一条 测绘范围
Article 1 Surveying and mapping scope
第二条 测绘内容
Article 2 Surveying and mapping content
第三条 执行技术标准
Article 3 Standards of technology implementation
第四条 测绘工程费
Article 4 Engineering fees of Surveying and mapping
第五条 甲方的义务
Article 5 Party A’s obligations
第六条 乙方的义务
Article 6 Party B’s obligations
第七条 测绘项目完成工期 Article 7 Completion term of the surveying and mapping projects
第八条 测绘成果验收
Article 8 Acceptance of surveying and mapping results
第九条 测绘成果权属
Article 9 Ownership of surveying and mapping results
第十条 费用支付
Article 10. Payment of fees
第十一条 交付测绘成果
Article 11 Submission of surveying achievements
第十二条 甲方违约责任
Article 12 Liability for Party A’s breach of contract
第十三条 乙方违约责任
Article 13 Party B’s liability for breach of contract
第十四条 不可抗力
Article 14: Force majeure
第十五条 其他约定
Article 15 Miscellaneous
第十六条 补充协议
Article 16, Supplementary Agreement
第十七条 争议处理
Article 17. Dispute settlement
第十八条 附则
Article 18 supplementary provisions
部分章节示例如下：
第五条 甲方的义务 Article 5 Party A’s obligations
1、自合同签订之日起 日内向乙方提交有关资料。
1. Submit relevant information to Party B within days from the date of signing the contract.
2、自接到乙方编制的技术设计书之日起 日内完成技术设计书的审定工作，并提出书面审定意见。 2. Complete the verification of the technical designs and submit written verification opinions within days from the date of receiving the technical designs prepared by Party B,.
3、应当保证乙方的测绘队伍顺利进入现场工作，并对乙方进场人员的工作、生活提供必要的条件。
3. Should ensured the Party B’s team of surveying and mapping enter the site smoothly and provide necessary or desirable conditions of the work and life for them.
4、甲方保证工程款按时到位，以保证工程的顺利进行。 4. Party A guarantees the project funds in place on time to ensure the smooth progress of the project.
5、允许乙方内部使用执行本合同所生产的测绘成果。 5. Allow and permit Party B internally use the surveying and mapping results which produced by implementation of the present contract.
第六条 乙方的义务 Article 6 Party B’s obligations
1、自收到甲方的有关材料之日起 日内，根据甲方的有关资料和本合同的技术要求，完成技术设计书的编制，并交甲方审定。
1. Within days from the date upon receipt of Party A's relevant data and documents, make completion of preparation of the technical design document in accordance with Party A's relevant data and documents and the technical requirements hereof and submit the same to Party A for approval.
2、自收到甲方对技术设计书同意实施的审定意见之日起 日内组织测绘队伍进场作业。
2. Organize the surveying and mapping team access the site for operation within days from the date upon receipt of Party A's approval opinion on implementation of the technical design document.
3、乙方应当根据技术设计书要求确保测绘项目如期完成。
3. Party B shall ensure the surveying and mapping project being completed on schedule in accordance with the requirements of the technical design document.
4、允许甲方内部使用乙方为执行本合同所提供的属乙方所有的测绘成果。
4. Party A is allowed to internally use the achievements and results of surveying and mapping provided by Party B for the execution of this contract.
5、未经甲方允许，乙方不得将本合同标的的全部或部分转包给第三方。
5. Without Party A’s permission, Party B shall not subcontract whole or any part of the present contract to third party.
第七条 测绘项目完成工期 Article 7 Completion term of the surveying and mapping projects
第八条 测绘成果验收
Article 8 Acceptance of surveying and mapping results
乙方应当于工程完工之日起 日内书面通知甲方验收，甲方应当自接到完工通知之日起 日内，组织有关专家，依据本合同约定使用的技术标准和技术要求，对乙方所完工的测绘工程完成验收，并出具测绘成果验收报告书。
对乙方所提供的测绘成果的质量有争议的，由测区所在地的省级测绘产品质量监督检验站裁决。其费用由败诉方承担。
Party B shall notify Party A in writing of acceptance within day of completion of the project. Party A shall, within day of receiving the notice of completion, organize relevant experts, in accordance with the technical standards and technical requirements stipulated herein, complete the acceptance of the surveying and mapping project completed by Party B, and issue the acceptance report of surveying and mapping results.
Any dispute over the quality of surveying and mapping achievements provided by Party B shall be appealed the provincial supervision and inspection station of surveying and mapping product quality in the location of the survey area for judgment and the charges thereof shall be borne by the losing party.
第九条 测绘成果权属
Article 9 Ownership of surveying and mapping results
对乙方测绘成果的所有权、使用权和著作权归属的约定： The agreement on ownership, right of use and copyright ownership of Party B's achievements of surveying and mapping:
第十一条 交付测绘成果
Article 11 Submission of surveying achievements
1、自测绘工程费全部结清之日起 日内，乙方根据技术设计书的要求向甲方交付全部测绘成果。
1. Party B shall, within days from the date of full settlement of surveying and mapping works, submit all achievements and results of surveying and mapping to Party A as the requirements of the Technical Design document.
乙方向甲方交付全部测绘成果表。
Party B shall submits to Party A all achievements and results of surveying and mapping.
乙方向甲方交付约定的测绘成果 份。甲方如需增加测绘成果份数，需另行向乙方支付每份工本费 元。
Party B shall submit to Party A copies of the agreed achievements and results of surveying and mapping. If Party A needs more copies thereof, Party A shall pay yuan of separate cost of each copy to Party B.
第十二条 甲方违约责任
Article 12 Liability for Party A’s breach of contract
1、合同签订后，乙方未进入现场工作前，由于甲方工程停止而终止合同的，甲方无权请求返还定金。双方没有约定定金的，偿付乙方预算工程费的30%，人民币 元；乙方已进入现场工作，甲方应按完成的实际工作量支付工程价款，并按预算工程费的 %（ 元）向乙方偿付违约金。
1. On time after the signing of the contract and Party B do not enter the site for operation, Party A has no right to request return of the deposit if Party A terminates the contract due to termination of its project. If the parties fail to agree on a deposit, shall pay Party B 30% of the project budget costs equal to RMB; provided that if Party B has entered the site work, Party A shall pay the project price subject to the actual workload completed, and shall pay Party B a penalty for breach of contract at % ( yuan) of the project budget costs.
2、乙方进场后，甲方未给乙方提供必要的工作、生活条件而造成停窝工时，甲方应支付给乙方停窝工费，停窝工费按合同约定的平均工日产值（ 元/日）计算，同时工期顺延。
2. Provided that if, subsequent to Party B enters the site, Party A fails to provide Party B with the necessary working and living conditions, which results in the suspension of work for which Party A shall disburse or make payments of to Party B’s suspension of work, which shall be calculated according to the average daily output value ( yuan / day) stipulated in the contract, and the construction period shall be postponed.
